Delhi High Court : only in cases where damage or loss is difficult or impossible to prove that the liquidated amount named in the contract, if a genuine pre-estimate of damage or loss, can be awarded.

Bhopal Dal Udyog v. Food Corporation Of India (Delhi High Court, Division Bench, decided on 04.01.2022), 

The Arbitrator had awarded Liquidated Damages (LD) in favour of the Respondent, relying on clause of the Agreement between the parties, in addition to the actual loss suffered by the Respondent (which was proved), as a result of the breach of Contract by the Appellant. 

The Court observed as follows:-

1. Section 74 of the Indian Contract Act, 1872 provides that when a sum has been named in a contract, as the amount to be paid on breach, the party complaining of breach is entitled, whether or not actual damage or loss is proved to have been caused, to receive from the party in breach, reasonable compensation not exceeding the amount so named. (Commonly called LD)

2. Such a sum named in the contract, is payable only if it is a genuine pre-estimate of damages, fixed by both parties, and found to be such by Court/arbitrator.

3. The expression "whether or not actual damage or loss is proved to have been caused thereby" means that where it is possible to prove actual damage or loss, such proof is not dispensed with. It is only in cases where damage or loss is difficult or impossible to prove that the liquidated amount named in the contract, if a genuine pre-estimate of damage or loss, can be awarded.

4. In the Present case as the actual damages suffered by the respondent were proven and accepted by the #Arbitrator, LD over and above such actual damages could not have been awarded.

(Reliance placed on Kailash Nath Associates v. DDA & Anr., (2015) 4 SCC 136)

On the basis of above, the Arbitral Award was set aside to the limited extent of the Liquidated Damages being awarded over and above the actual damages.

Provisions of the special Act always override the provisions of the general law

 In the Matter of M/s Apex Buildwell Pvt. Ltd. V/s Sachin Kumar,Appeal No.240 of 2019 decided on 09.02.2021 before THE HARYANA REAL ESTATE APPELLATE TRIBUNAL it was held that

"We do not find any substance in the contentions raised by learned counsel for the appellant that in order to claim the compensation for delay in delivery of possession, the respondent /allottee was required to establish the loss suffered by him as provided in Section 74 of the Indian Contract Act, 1872. The provisions for grant of damage on account of the breach of contract provided in Section 74 of the Indian Contract Act are the general provisions. Whereas Section 18 of the Act is a special provision dealing with consequences on account of the failure of the promoter to complete the project by the date specified in the agreement for sale. The proviso to Section 18(1) of the Act categorically provides that where an allotee does not intend to withdraw from the project, he shall be paid by the promoter the interest for every month of delay till handing over of the possession at such rate as may be prescribed. Thus, the proviso to Section 18(1) of the Act stipulates that the allottee shall be entitled to interest at the prescribed rate for the delay in delivery of possession beyond the date stipulated in the agreement for sale. It is nowhere mentioned in Section 18 of the Act that in order to claim the interest for delayed delivery, the allottee has to prove the loss. Simple failure of the promoter to deliver the possession by the date specified in the agreement for sale, will make the allottee entitled for the interest provided in the proviso to Section 18(1) of the Act. It is settled rule of interpretation that the provisions of the special Act always override the provisions of the general law. So, the provisions of the Act will override Section 74 of the Indian Contract Act which is the general law."