BOMBAY HIGH COURT - The liability of refund falls upon all the listed promoters even if they may not have received the amount in consideration.

BOMBAY HIGH COURT - The liability of refund falls upon all the listed promoters even if they may not have received the amount in consideration.

Wadhwa Group Housing Private Ltd vs Vijay Choksi & SSS Escatics Pvt. Ltd

SECOND APPEAL (Stamp) NO. 21842 OF 2023

Decided on 26 February 2024

IN THE HIGH COURT OF JUDICATURE AT BOMBAY

Time line of the Matter :-

1. Allottee approached MahaRERA U/s 12 and 18 of the RERA act and sought refund of amount of Rs.2,62,35,056/- along with interest as well as compensation and costs.
2. On 24/09/2021 MahaRERA passed the Order holding that Allottee could not claim any equity under the provisions of act and his prayer for refund was rejected, and directed parties to execute registered agreement for sale within 30 day failing which the entire amount was directed to be refunded to the Allottee within six months.
3. Allottee filed Appeal U/s 43 of the RERA Act before the Appellate Tribunal.
4. On 18/10/2022 Appellate Tribunal partly allowed the appeal and set aside the Order directing both the Builders to Jointly refund the amount paid by the Allottee with interest.
5. Aggrieved by the Appellate Tribunal’s Order to put the liability to refund the amount received by SSS Escatics Pvt. Ltd the other Builder Wadhwa Group Housing Private Ltd chose to file this appeal.

Question of Law Framed in Second Appeal

"Whether a promoter who has not received any consideration from an allottee can be made liable for giving refund with interest under Section 18 of the Real Estate (Regulation and Development) Act, 2016?"

Fact of the Case:-

1. Builder SSS Escatics Pvt. Ltd, launched a project called “The Nest” as a Slum Rehabilitation Scheme.
2. On 05/09/2012 A JDA (Joint Development Agreement) came to be executed between both the Builders SSS Escatics Pvt. Ltd and Wadhwa Group Housing Private Ltd.
3. Under the said JDA Wadhwa and SSS segregated the constructed area amongst themselves for being sold to customers.
4. On 19/07/2013, Allottee booked a 3BHK Flat bearing B-502 admeasuring 2385 sq.ft in the said project for agreed consideration of Rs.2,65,35,000/-
5. Allottee paid an amount of Rs.1,20,00,000/- towards part consideration.
6.  On 24/07/2013 SSS issued allotment letter to Allottee.
7. The project remained incomplete on the date of coming into force of RERA Act, 2016.
8. The project was accordingly registered as ongoing project under Section 3 of the RERA by SSS in which the Wadhwa was declared as a Promoter (Investor).

Submissions by Appellant

1. Wadhwa cannot be held responsible for refund of any amount to the Allottee as he has not paid any amount to the Wadhwa and that therefore there is no question of refunding any amount to him.
2. As per the JDA both builders identified their respective entitlements in constructed portion of the building and the flat in question falls in the share of SSS, and it  alone received the entire consideration from the Allottee thereby no question of Wadhwa refunding the amount which it did not receive.
3. Mere a change in law requiring reflection of name of wadhwa as Promoter does not create its liability, which did not exist prior to introduction of RERA.  

Submissions by Respondent

1. Wadhwa is undoubtedly covered by definition of the term ‘Promoter’ per se Section 2(zk) of RERA.
2. Definition U/s 2(zk) makes it clear that all promoters are jointly liable under the Act.
3. That a promoter cannot be permitted to defeat the rights of the flat purchasers by making internal arrangements with investors, land owners, etc 

observations made by the Hon’ble Court

1. There appears to be no dispute that the payments were made by the Allottee to the SSS.
2. it is necessary to determine whether Wadhwa falls in the definition of the term ‘promoter’.
3. While registering the project as ongoing project under Section 3 of the RERA, Wadhwa’s name has been included in the list of Promoters. Therefore, Wadhwa cannot run away from the fact that it is the promoter in respect of the project ‘The Nest’
4. Mere falling of flat in the share of the SSS under the JDA would not excuse the Wadhwa from the responsibilities and liabilities under the RERA, Rules and Regulations made thereunder qua that flat. 
5. RERA does not demarcate or restrict liabilities of different promoters in different areas and the liability is joint for all purposes under the Act, Rules and Regulations
6.  Since the Wadhwa is covered by definition of the term ‘Promoter’, it is also jointly liable to refund the amount along with the SSS.
7. Distinction between projects launched before and after coming into force of RERA cannot be a ruse to escape the liabilities as promoter under RERA.
8. The Wadhwa’s contention about absence of privity of contract between it and the Complainant is totally misplaced as it is a matter of indoor management between the Promoters and the flat purchaser who is not supposed to know the intricacies of the arrangements made between several promoters amongst themselves.

Court’s Order

Accordingly the Second Appeal is accordingly dismissed with costs.

In the Second Appeal , BOMBAY HIGH COURT upheld the Condonation of Delay granted by the MAHAREAT Stating that It is not unnatural for a flat purchaser, who had book the flat in 2011 and was yet to receive possession in 2018, to feel anxious especially when he was not permitted to inspect the flat.

In the Second Appeal , BOMBAY HIGH COURT  upheld the Condonation of Delay granted by the MAHAREAT Stating that It is not unnatural for a flat purchaser, who had book the flat in 2011 and was yet to receive possession in 2018, to feel anxious especially when he was not permitted to inspect the flat.

Lucina Land Developers Limited V/s Navin Kumar

SECOND APPEAL NO.585 OF 2020

Decided on 27 MARCH 2024

IN THE HIGH COURT OF JUDICATURE AT BOMBAY

Question of Law framed in 2nd Appeal :-

“Whether the Appellate Tribunal was justified in condoning the delay of 395 days in filing the appeal by the original complainant (Respondent herein)?

Time line of the Matter :-

1. Respondent (Allottee) filed Complaint before the Maharashtra Real Estate Regulatory Authority, (Maharera) complaining non-delivery of possession within the agreed period and claimed interest under provisions of section 18 of the Maharashtra Real Estate (Regulation and Development) Act, 2016 (RERA).
2. On 13/12/2017 Maharera disposed of the complaint holding that the Allottee failed to establish that the Appellant did not complete the project or was unable to deliver possession of the Apartment in accordance with the Agreement and directed the Appellant to handover possession of the Apartment with occupancy certificate to Allottee before 31 December 2018, failing which the Appellant was directed to pay interest as per Rule 18 with effect from 1 January 2019 till the actual date of possession on the entire amount paid by the Allottee. 
3. On 11/01/2019 Allottee filed Appeal before the Maharashtra Real Estate Appellate Tribunal (Appellate Tribunal)  challenging the order along with an application seeking condonation delay in filing the appeal. 
4. On 19/08/2019 the Appellate Tribunal  allowed the application for condonation of delay.
5. The Appellant has filed this Second Appeal challenging the judgment and order dated 19th August 2019 passed by the Appellate Tribunal.

Fact of the Case :-

1. Allottee  purchased an apartment bearing No.203 in the project India bulls Greens-II situated at Panvel and Entered into Flat Buyer's Agreement on 18/10/2011.
2. As per the Flat Buyer's Agreement, possession was to be handed over within 60 months with grace period of 9 months.

Contentions of Appellant :-

1.  The Appellate Tribunal has committed a manifest error in condoning inordinate delay of 395 days in filing the Appeal.
2. Allottee  was not prevented by any disability or cause from filing the Appeal within the period of limitation.
3. Allottee took a false plea of heart disease, which was relatable to the year 2016.

Contentions of Respondent :- 

1. No substantial question of law is involved in the present Appeal as the impugned order merely condones delay of 395 days in filing the Appeal.
2. That Condonation of delay is the discretionary power exercised by the Appellate Court in which this Court cannot interfere in exercise of jurisdiction under Section 100 of the Code of Civil Procedure (Code).
3.  Technicalities cannot be permitted to overtake the substantive rights sought to be agitated by a flat purchaser.
4. That Allottee suffers from serious cardiac ailments for prolonged time, which is evidenced in various certificates produced before the Appellate Tribunal. 
5. That Allottee also faced financial distress on account of health issues suffered by him
6. The Allottee has excellent case on merits, and the same cannot be thrown out on the ground of limitation without considering the merits involved in the Appeal.

Observations of the High Court:-

1. The short issue that requires consideration in the present Appeal is about correctness of the order passed by the Appellate Tribunal in condoning delay of 395 days in filing the Appeal.
2. Condonation of delay is a matter of discretion to be exercised by a Court. So long as exercise of discretion is sound, the Appellate Court shall not substitute its discretion with the discretion exercised by the Court condoning the delay 
3. it cannot be stated that there is complete absence of any cause in the application. Respondent, in his capacity as a flat purchaser first made an attempt to prosecute his complaint personally considering the ease of access provided to parties-in-person before Regulatory Authority.
4. There is sound exercise of discretion by the Appellate Tribunal in condoning the delay. So long as the exercise of discretion by the Appellate Tribunal is not arbitrary, interference by this Court in exercise of discretion is clearly unwarranted.
5.  the Respondent repeatedly pursued various issues with Appellant after passing of the order by the Regulatory Authority. The email correspondence started from 24 February 2018 and went on till 4 December 2018. Most of the emails were in respect of permission to visit the flat, since the Respondent believed that the same was not habitable
6. It is not unnatural for a flat purchaser, who had book the flat in 2011 and was yet to receive possession, to feel anxious especially when he was not permitted to inspect the flat.

Order of the High Court:-

1. the Appellate Tribunal was justified in condoning the delay in filing the Appeal by Respondent.
2. The Second Appeal is accordingly dismissed without any orders as to costs. 

FIR by Maharashtra RERA Against Builder after forensic audit for Non Compliance and Misappropriation U/s 4,406,409,420

FIR by Maharashtra RERA Against Builder after forensic audit for Non Compliance and Misappropriation.

On the Date 23/02/2024 , On the Directions of the Maharashtra RERA, the administrative officer Lodged the FIR u/s 34,406,409,420 against the

1. PARAMVIR DEVELOPERS LLP
2. KUMAR KANAYALAL MORDANI (Director) and
3. KANAYALAL MORDANI (Director)

Timeline of the Matter

1. On Date 11/01/2023 Maharashtra Real Estate Regulatory Authority (Maharera) sent a letter to PARAMVIR DEVELOPERS LLP dated regarding non compliance of its rules.
2. Again On Date 27/02/2023 another letter was sent to Builder dated regarding non compliance.
3. No reply received from the Builder.
4. Due to No Reply by the Builder,  On Date 14/03/2023 ,a company named Neelam Arch Consultant was appointed as an investigator for the Builder's Project High street (Maharera Registration No. 51800005582)
5. The investigator was not allowed access to the site by the Builder.
6.  On the Intervention of Maharera only the Investigator was given access to the said site
7. After studying the site the Investigator submitted a report to Maharera on 23/03/2023.
8. On Date 24/03/2023, Maharera sent a letter to Builder regarding non-filing of any return but again the builder did not respond.
9. On Date 02/05/23, Maharera decided to appoint M/s BDO India LLP to conduct a forensic audit of Builder's high street project .
10. The company B.D.O. India. LLP submitted the report in this regard to Maharera on 25/08/2023.

The Forensic Audit Report revealed the Followings:-

• The Builder collected a total of Rs.19.82 crores from the customers and deposited the entire amount in the current account of his firm and not in the Separate RERA bank as mandated U/s section 4(2)(l)(d).
• Out of Total Rs.19.82 crores received by the developer from the customers, an amount of Rs.11.61 crores is given as Interest free loan and advance to other Sister companies/firms without any agreement and document.
• The Builder raised a loan of Rs. 202.33 crores  from Banks and Financial Institutions for the said project.

• Out of the total loan amount raised, Rs. 66.43 crores is given as Interest free loan and advance to other Sister companies/firms without any agreement and document.

•  A total of Rs 109.13 crore was repaid to the financial institutions even before completing the project.

• There by The Builder misappropriated a total amount of Rs 78.04 crore.
• Only an amount of Rs. 6.40 crores was used under the project expenses in the ledger books.

• The developer had taken bookings for the project from 34 customers. On verification of the customer ledger and sales ledger from the developer, it was seen that the booking amount of five customers was 220 crores, but due to cancellation of their bookings, the amount refunded to them was only Rs. 2.83 crores. This raised doubts about the refund amount.

• Since 2017 the developer did not submitted  any quarterly report.

• The developer constructed a thirteen storied RCC against a permission of a six storied building. 

• The developer only completed 30 % of the project by December 2022.

Thus Resulting in the FIR against the Builders and its Directors.

TSRERA :- The Allottee has an obligation to adhere to the payment schedule as agreed in its Agreement of Sale as per Section 19(6) and non procurement of the Home loan amount cannot put the Builder under financial distress.

The Allottee has an obligation to adhere to the payment schedule as agreed in its Agreement of Sale as per Section 19(6) and non procurement of the  Home loan amount cannot put the  Builder under financial distress. 

Sri Umesh Choudhary Vs/ M/s Alpine Infratech 

COMPLAINT NO.519 OF 2023 decided on 12th Day of March, 2024 

BEFORE TELANGANA STATE REAL ESTATE REGULATORY AUTHORITY

Facts :-

1. The Complainant booked a flat in August 2021 in the project of the Respondent Builder.
2. Application Form/Terms and Conditions of Allotment was signed by him.
3. The Agreement of Sale was executed in the month of January 2022.
4. Complainant paid 20% of the cost and the balance 80% amount was to be arranged in form of Home loan.
5. The Project was approved from many nationalized bank but as the Complainant was a Central Government employee so he wanted the Home Loan in the form of House Building Allowance (HBA) from his concerned department. 
6. That vide e-mail dated 15.04.2022, the Complainant sought for several documents ( a list of 19 documents) from the Respondent Builder to avail HBA loan.
7. The complete documents were finally given by the builder on 20.02.2023.
8.  The Builder directed the Complainant to pay the Final due amount by 28.03.2023 else base price will be increased by Rs.200 per sft.
9. The Complainant offered an interim payment of Rs.5,00,000/-  by first week of May 2023 and the full payment by July 2023.
10. In May 2023, the Complainant requested the builder to accept the due amount of Rs.25,00,000/-
11. The Builder refused to accept the amount and stated that they will only accept if the Complainant agreed to make the payment with the revised base rate by Rs. 1000 per sft an increase of  Rs.11,20,000 in total price. 

Complainants Contentions :-

1. The delay in making payment occurred due to non-handing over of documents in time. hence, management is responsible for such delays.
2.  The revised increased rate is not acceptable as the delay in making payment did not occur on default of the Complainant. 
3. Prayed to take needful action against the Respondent Builder as per the applicable rules and regulations and to get the flat at the original agreed rate.

Respondent Builder's Contentions :-

1. The Complainant in spite of availing discount did not pay the agreed amount on time.
2. The Complainant initially agreed orally to take loan from various nationalized banks but later in the month of July 2022, started requesting various documents from the Respondent Company
3. The Complainant made one or the other request for the documents and that too after a lapse of one year and also which were beyond the purview of the Respondent Company and evaded the payments due to the Respondent Company. 
4. The Respondent Company sent several mails requesting the Complainant to visit the office of the Respondent Company to sort the issue. 
5. The Complainant failed to perform his part of contractual obligation and did not make the payment as per schedule, that's why the Company is justified in cancelling the booking 

Observations of the Authority :-

1. In Clause 1.3 of the BBA, the Complainant agreed to make payment as per payment plan set out in Schedule C (Payment Plan).
2. As per the Payment Schedule annexed to the said Agreement of Sale, the Complainant categorically agreed to payment of the schedule therein. which is not disputed by either party 
3. in the annexure to the said Payment Schedule, Point No.4 stipulates that prices are subject to change without prior notice upon non confirmation of sale.  
4.  the Complainant is bound by the same and failure of the Complainant in complying with the payment schedule is derogation of his duty under Section 19(6) of the Act.
5. the delay in procuring the documents cannot be attributed to the Respondent Builder as the said documents may not readily available with him and he may not be in a position to produce documents such as 
1. government pleader's certificate, 
2. estimates, 
3. permission under Conduct Rules for purchase of site and for construction of the house,
4.  Notice under Section 26(1) of the Urban Land (Ceiling & Regulation) Act, 1976, etc
6. Clause 9.3 (ii) of the undated Agreement of Sale executed between the parties clearly stipulates In case of Default by Allottee under the condition listed above continues for a period beyond 2 (two) consecutive months after notice from the Promoter in this regard, the Promoter may cancel the allotment of the [Apartment/Plot] in favor of the Allottee and refund the money paid to him by the allottee by deducting the booking amount and the interest liabilities and this Agreement shall thereupon stand terminated

Order of Authority:-

1. The Complainant is directed to pay the remaining amounts which is pending as on date as per the payment schedule agreed upon by both the parties within 60 (sixty) days, along with interest of 10.65%.
2. In the event the Complainant fails to complete such payment, the Respondent is to initiate measures in accordance with the provisions of the Act and Rules thereunder.